How We work Together
MW Builders Ltd will use the reasonable skill and care expected of a Master Builder. We will construct and complete the works so they comply with relevant standards and satisfy regulatory authorities. We will rectify any defects in the works for 6 months after completion. We will act honestly and in your best interests. We will (and will require our employees and subcontractors to) treat you and your property with respect. We will keep your property safe, clean and a healthy working environment. However, as a construction site, we will create dust, noise and vibrations as we carry out the project. We will comply with all relevant laws and health and safety legislation. We currently hold appropriate levels of insurance cover for public liability, employer’s liability and contractor’s all risks for your project. We will carry out the works regularly, working on Mondays to Fridays from 8am to 5pm and make reasonable progress. We will update you regularly on the progress of the project. Once the work is substantially complete we will:
- Leave your property clean, tidy and ready to use/occupy
- Legally dispose of all waste
- Provide you will relevant instructions, product guarantees, warranties and a certificate that the works are complete
- Outline any maintenance or operating issues you need to be aware of, and
- Agree a date to return to your property to make good any minor defects or snagging items which arise within 6 months after completion.
What We Can Do
We may supply you with samples of materials, goods and fittings for your approval. Once approved, if you later change your mind, this may result in you incurring extra costs. All materials, goods and fittings will be of satisfactory quality, reasonably fit for their purpose and match any samples provided. We may subcontract elements of the works. If we do, we are responsible for those subcontractors and for their work.
What We Are Not Doing
We are not providing:
- Advice on your obligations under the Party Walls Act or CDM Regulations
- Advice on any design provided to us for the works. You and your designers are responsible for checking that the design meets your requirements
- Relevant notices to the relevant Authorities
Your Responsibilities
You will pay our invoices quickly and fairly upon receiving. If you do not pay our invoices within 14 days, we can charge simple interest at 5% above the current base rate. You will provide us with access to your property which will be unrestricted and exclusive – unless the Offer says otherwise – and you will keep the working area free from personal possessions and obstructions. You will generally check progress of the works and that it continues to meet your requirements, or let us know if you appoint someone to do so on your behalf. You may not employ others to work on the project or your property without telling us first as we have overall responsibility for safety.
Changes During the Project
We will inform you of any unforeseen problems or delays as early as possible and discuss how these affect your aims for the project. If you ask us to make any changes to the works, we will confirm these in writing as well as any extra costs or time involved. We will jointly agree the new price before we carry out the changes. If we cannot agree the extra costs involved, you may ask us not to carry out the changes. If you ask to continue but don’t agree a price then we may add a fair and reasonable sum to our next invoice.
If Things Go Wrong
Our liability for any loss or damage you suffer as a result of us carrying out the works is limited to the sum stated in the Offer. If a dispute arises we will try and resolve it by discussing it with you. If we cannot resolve it then we both agree to use the FMB Complaint Service. The laws of England and Wales apply to this agreement and the courts of England and Wales have jurisdiction and enforcement powers.
Ending Works agreed
If you decide to cancel the project once work has started, you must give us at least one months’ written notice that you want us to stop carrying out the works. You must pay all costs that we have incurred to the date we leave your property, as well as compensation towards our lost profits. If either of us is in serious breach of its obligations under this agreement, the other may ask them to rectify that breach within two weeks and, if they do not, can terminate this contract by written notice. Upon any termination, both of us will take steps to bring all work in progress to an orderly conclusion. We will invoice you for any sums remaining due which you will pay within 14 days.
Promotional Material
MW builders reserve the right to document all works before, during and on completion for marketing, training and promotional purposes. If would prefer that we did not collect visual information then you are free to opt out. All requests must be submitted in a written format such as text or email.
